Mobile Application Development Service Agreement
Attention!
The Law and Law Law Company draws your attention to the fact that this document is basic and does not always meet the requirements of a specific situation. Our lawyers are ready to assist you in drafting any legal document that suits your situation. For more information, please contact a Lawyer/Lawyer by phone; +7 (708) 971-78-58; +7 (727) 971-78-58.
AGREEMENT No. 18
provision of mobile application development services
"................." Almaty city dated March 06, 2021
<Name of the legal entity,> <residence, date of establishment, certificate of registration, date and number, by whom it was registered> , hereinafter referred to as the “Contractor”, represented by <position, F.,I.,O. of the person signing the contract>, acting on the basis of <charter, regulations, power of attorney N_____ from "_____"__________200___ on the one hand, and <name of the legal entity,> <residence, date of establishment, certificate of registration, date and number, by whom it was registered or F.I.Oh. individual, nationality, residence, number and date of the identity document>, hereinafter referred to as the “Customer”, represented by _______________________________________________________, acting on the basis of _________________, on the other hand, hereinafter referred to as the Parties, have concluded this Agreement on the following:
Subject of the Agreement
1.1. Provision of services for the development of the Atasu Express mobile application, in accordance with the Annexes to this Agreement, which are an integral part of the agreement. 1.2. The Contractor undertakes to transfer the result of the rendered services to the Customer's ownership, and the Customer shall pay for and accept the rendered services in quantity and quality in accordance with the Annexes to this Agreement, which are an integral part of this Agreement.
Mobile Application Development Service Agreement
1.3. The date of completion of the work for each stage determined by the Calendar Plan is the date of signing by the Parties of the relevant Act of Delivery and acceptance of the completed works of each stage with the attachment of accounting documents, also specified in the Calendar Plan. The date of fulfillment of obligations to perform Work under the Contract as a whole is considered to be the date of signing by the Parties of the Act of Delivery and Acceptance of the Work performed at the last stage. 1.4. If, during the execution of the Work, any Party needs to make individual changes to the Work Schedule that may affect the deadline for completion of the completed work as a whole, such changes should be immediately discussed by the Parties and, if agreed, made in writing and signed by both Parties.
Cost of services and payment procedure
2.1. The total cost of the Works constituting the subject of this Agreement is __________ tenge, including all taxes and fees. 2.2. The cost of services under the Agreement includes all Contractor's expenses related to the fulfillment of obligations under the Agreement, including transportation, insurance, customs duties, taxes, fees and other mandatory payments, and other Contractor's expenses related to the fulfillment of the Agreement. The cost of services under the Contract is fixed and unchangeable throughout the entire term of the contract. 2.3. Payment for the completed Works will be made by the customer for each completed and accepted stage of Work, determined by the Calendar Plan within 7 (seven) calendar days from the date of signing by both parties of the act of delivery and acceptance of the completed Works.
Mobile Application Development Service Agreement
2.3. Payment is made in tenge, by non-cash transfer of funds by the Customer to the Contractor's current account, within 7 (seven) calendar days after the signing by both parties of the act of delivery and acceptance of the services rendered.
Obligations of the parties
3.1. The Contractor undertakes to: 3.1.1. Provide services for the development of a mobile application ".............." in accordance with the Annexes to this Agreement, of good quality. Within the time limit set by the Calendar Plan. 3.1.2. To issue all documents for the transfer of the results of the rendered services to the Customer. 3.1.3. Coordinate actions with the Customer. Undertaken in order to fulfill this Agreement. 3.1.4. To fulfill in full all its obligations stipulated in other clauses of this Agreement. 3.1.5. To provide the Customer with the opportunity to monitor the progress and quality of services provided by the Contractor. 3.1.6. Eliminate, at its own expense, the deficiencies and other defects identified by the Customer during the monitoring of the provision of Services. 3.1.7. Provide the Customer, upon request, with documents related to the fulfillment of obligations under the Agreement. 3.1.8. Immediately notify the Customer of any changes to their banking details specified in this Agreement. The changes will take effect upon receipt of a written notification by the Customer. 3.1.9. In the event of a change in bank details, the Contractor is obliged to notify the Customer in writing within three days from the date of their change, indicating the new details of the current account. Otherwise, all risks associated with the transfer of funds to the Contractor's account specified in this Agreement are borne by the Contractor. 3.2. The Customer undertakes 3.2.1. To accept the Services provided by the Contractor in accordance with the acceptance certificate and to pay for them in accordance with the terms of this Agreement. 3.2.2. To verify the Services provided for compliance with the Annexes to this Agreement. 3.2.3. To assist the Contractor in the provision of Services to the extent and on the terms stipulated in the Contract. 3.2.4. To provide the Contractor, upon his written request, with the information necessary for the provision of Services. 3.2.5. To inform the Contractor of the identified defects in the quality of the Services provided. 3.3. The Contractor has the right 3.3.1. To request from the Customer the information necessary for the provision of Services. 3.3.2. To demand payment for properly rendered Services in accordance with Section 2 of this Agreement. 3.4. 3.4.1. The Customer has the right to request the provision of information related to the provision of Services under this Agreement. 3.4.2. Request the elimination of defects (defects) discovered during the acceptance of the services provided during the warranty period at the expense of the Contractor. 3.4.3. Delay payment for services rendered until the identified deficiencies (defects) are eliminated.
Terms, procedure for rendering and acceptance of services rendered
4.1. Acceptance of the results of the rendered services, for each stage determined by the Calendar Plan, is carried out by the acceptance commission appointed by the Customer with the participation of a representative (representatives) The performer.
Mobile Application Development Service Agreement
4.2. The Acceptance Commission, which has received the Contractor's notification of readiness to deliver the results of the services rendered, is obliged to start accepting them within 3 (three) business days. 4.3. Acceptance of services is carried out no more than 2 working days. 4.4. Based on the results of the acceptance of the rendered services, the acceptance commission draws up and signs an act of acceptance and delivery of the rendered services. 4.5. If deficiencies (defects) in the results of the services provided are detected during the acceptance of the services provided, the Customer and the Contractor jointly draw up a protocol that records the list of deficiencies (defects) and the time frame for their elimination by the Contractor, as well as the date of re-acceptance of the services provided. 4.6. The Contractor is obliged to eliminate all detected deficiencies (defects) at its own expense the dates specified in the protocol. 4.7. The date of acceptance of the rendered services is the date of signing the acceptance certificate. 4.8. The Contractor does not proceed to the next stage of Work according to the Calendar Plan, until the signing of the Act of delivery and acceptance of Work on the current stage.
Quality assurance
5.1 The Contractor guarantees the quality and safety of the entire volume of services provided in accordance with the Annexes to this Agreement and the requirements of the current legislation of the Republic of Kazakhstan. 5.2 The warranty period is 1 (one) month from the moment of signing the acceptance certificate of the rendered services.
Responsibility of the parties
6.1. The Parties are responsible for non-fulfillment or improper fulfillment of their obligations under the Agreement in accordance with the current legislation of the Republic of Kazakhstan. 6.2. In case of delay in the fulfillment by the Contractor of its obligations stipulated in the Contract, the Customer shall collect a penalty (fine, penalties). The penalty (fine, penalties) is accrued for each day of delay in fulfilling the obligation starting from the day following the expiration date of the deadline for the last stage of the Calendar Plan. 6.3. The amount of the penalty (fine, fine) is set at 1 (one) % of the cost of the services provided (clause 2.1 of this Agreement). 6.4. The Contractor is exempt from paying the penalty (fine, fine) if he proves that the delay in fulfilling the specified obligation occurred due to force majeure or the fault of the Customer.
Mobile Application Development Service Agreement
Attention!
Law and Law Law Law draws your attention to the fact that this document is basic and does not always meet the requirements of a particular situation. Our lawyers are ready to assist you in legal advice, drawing up any legal document suitable for your situation.
For more information, please contact a Lawyer / Attorney by phone: +7 (708) 971-78-58; +7 (700) 978 5755, +7 (700) 978 5085.
Attorney at Law Almaty Lawyer Legal Services Legal Advice Civil Criminal Administrative Cases Disputes Protection Arbitration Law Firm Kazakhstan Law Office Court Cases
